495 Java Drive (Sunnyvale, CA) Agreement of Purchase and Sale - Network Appliance Corp. and 495 Java Drive Associates LP
AGREEMENT OF PURCHASE AND SALE
THIS AGREEMENT OF PURCHASE AND SALE ("Agreement") is entered into
as of June 11, 1998, by and between Network Appliance, Inc., a Delaware
Corporation ("Buyer"), and 495 Java Drive Associates, L.P., a California Limited
Partnership ("Seller") and constitutes (i) a contract of purchase and sale
between the parties and (ii) escrow instructions to Escrow Agent (as hereinafter
THE PARTIES ENTER INTO THIS AGREEMENT on the basis of the following
facts, understandings and intentions:
A. Seller owns and desires to sell to Buyer real property comprised of
approximately 5.86 acres, located at 495 Java Drive, Sunnyvale, California, as
more particularly described on EXHIBIT A attached hereto ("Land") and the
Improvements (defined below) being constructed by Seller, together with Seller's
interest in (i) all rights, privileges, easements and right-of-ways appurtenant
thereto, (ii) all warranties in connection with the Improvements, (iii) to the
extent assignable, all entitlements, permits and other intangible property used
in connection therewith, and (iv) to the extent assignable, all contract rights,
related to the ownership, use and operation thereof (collectively, including
such Land and Improvements, the "Property"), and Buyer desires to purchase the
Property from Seller, on all of the terms, covenants and conditions provided
B. For purposes of this Agreement, the following terms shall have the
meanings given below:
1. "Execution Date" shall mean the date set forth at the
2. "Business Day" shall mean any day other than a
Saturday, Sunday or day on which banks in the state of California are authorized
to be closed for business.
3. "Close of Escrow" shall mean the consummation of the
purchase of the Property by Buyer or Buyer's assignee from Seller and the
recordation of Seller's Grant Deed in accordance with the terms and provisions
of this Agreement.
4. "Closing Date" shall mean a date which is the earlier
of (i) twenty (20) business days following the date the Improvements are
substantially completed in accordance with the Work Letter or (ii) a date
selected by Buyer, but not before January 1, 1999, with written notice thereof
to Seller at least thirty (30) days in advance. Seller shall provide Buyer with
at least thirty (30) days written notice of the date Seller expects to
substantially complete the Improvements and written notice of the date such
Improvements are substantially complete.
5. "Escrow Agent" shall mean First American Title
Insurance Company, 1636 North First Street, San Jose, California 95112.
6. "Title Company" shall mean First American Title
Insurance Company, 1636 North First Street, San Jose, California 95112.
7. "Improvements" shall mean a four story building
consisting of approximately One Hundred Twenty-Six Thousand Seven Hundred Sixty
(126,760) square feet referred to in the Work Letter.
8. "Work Letter" shall mean that certain Work Letter
attached hereto as EXHIBIT B. Capitalized terms used herein and defined in the
Work Letter shall have the meaning given in the Work Letter.
9. "Lot Line Adjustment" shall mean adjustment of the
property line between the Property and the adjoining property at 475 Java Drive
in order to accommodate a common driveway as shown on Seller's Plans (as defined
in the Work Letter).
10. "CC&R's" shall mean covenants, conditions and
restrictions for the purpose for operating the Property and the adjoining
property at 475 Java Drive in a manner that allows a common driveway
substantially in conformance with the Declaration Of Covenants, Conditions And
Restrictions And Cross-Access Parking Agreement For 500 East Middlefield Road
and 401 Ellis Street, Mountain View, California dated December 12, 1997 and
recorded as Document No. 13979683 of the Santa Clara County, California records,
with appropriate revisions to adapt such document to the Property.
NOW, THEREFORE, IN CONSIDERATION of the mutual covenants and agreements
of the parties as herein set forth, the parties hereto agree as follows:
1. Purchase. Seller agrees to sell the Property to Buyer, and
Buyer agrees to purchase the Property from Seller, on all of the terms,
covenants and conditions provided herein.
(a) Deposit. Within seven (7) Business Days following the
Execution Date, Buyer shall deposit with Escrow Agent the sum of Five Million
Dollars ($5,000,000.00) in cash ("Deposit") as a deposit on account of the
Purchase Price (as defined in Section 4). The Deposit shall be nonrefundable,
except as provided in Section 3(b) below.
(b) Interest Bearing Account. Escrow Agent shall deposit
the Deposit in an interest bearing account, pursuant to investment instructions
from Buyer. All interest earned on the Deposit shall be for the account of
3. Liquidated Damages/Default.
(a) Buyer's Default. IN THE EVENT THAT THE SALE OF THE
PROPERTY DOES NOT CLOSE AS A CONSEQUENCE OF A DEFAULT BY BUYER, AND IF SELLER IS
NOT IN DEFAULT OF ITS OBLIGATIONS UNDER THIS AGREEMENT AND HAS PERFORMED ALL
OBLIGATIONS OF SELLER TO BE
PERFORMED HEREUNDER AS OF THE TIME OF BUYER'S DEFAULT, SELLER SHALL BE ENTITLED
EITHER TO (i) RETAIN THE AMOUNT OF THE DEPOSIT AS LIQUIDATED DAMAGES, OR (ii)
SPECIFIC PERFORMANCE OF BUYER'S OBLIGATION TO PURCHASE THE PROPERTY; PROVIDED,
HOWEVER, IN THE EVENT SELLER ELECTS TO SEEK SPECIFIC PERFORMANCE AND IS
UNSUCCESSFUL IN OBTAINING SPECIFIC PERFORMANCE SELLER SHALL BE ENTITLED TO
RETAIN THE AMOUNT OF THE DEPOSIT AS LIQUIDATED DAMAGES. THE PARTIES AGREE THAT
SELLER'S ACTUAL DAMAGES WOULD BE DIFFICULT OR IMPOSSIBLE TO DETERMINE IF BUYER
DEFAULTS, AND THE AMOUNT OF THE DEPOSIT (AND ACCRUED INTEREST THEREON) IS THE
BEST ESTIMATE OF THE AMOUNT OF DAMAGES SELLER WOULD SUFFER. THE PARTIES
ACKNOWLEDGE THAT THE SUM REPRESENTED BY BUYER'S DEPOSIT (AND INTEREST ACCRUED
THEREON) CONSTITUTES A REASONABLE ESTIMATE OF SELLER'S DAMAGES UNDER THE
PROVISIONS OF SECTION 1671 OF THE CALIFORNIA CIVIL CODE.
(b) Seller's Default. IF SELLER REFUSES OR FAILS TO CONVEY
THE PROPERTY PURSUANT TO THIS AGREEMENT FOR ANY REASON EXCEPT A DEFAULT BY BUYER
HEREUNDER, BUYER, AS ITS SOLE AND EXCLUSIVE REMEDY (EXCEPT AS PROVIDED IN
SECTION 6(f) BELOW), SHALL BE ENTITLED EITHER TO (i) TERMINATE THIS AGREEMENT
AND RECOVER THE DEPOSIT AND IF APPLICABLE THE LIQUIDATED DAMAGES COMPUTED
PURSUANT TO SECTION 6(e) BELOW, OR (ii) SPECIFIC PERFORMANCE OF SELLER'S
OBLIGATION TO CONVEY THE PROPERTY, PROVIDED THAT NO SUCH ACTION FOR SPECIFIC
PERFORMANCE SHALL SEEK TO REQUIRE SELLER TO DO ANY OF THE FOLLOWING: (A) CHANGE
THE CONDITION OF THE PROPERTY OR RESTORE THE SAME AFTER ANY CASUALTY (EXCEPT AS
EXPRESSLY PROVIDED IN SECTION 12), OR (B) EXPEND MONEY OR POST A BOND TO REMOVE
A TITLE ENCUMBRANCE OR DEFECT (EXCEPT LINES OR ENCUMBRANCES CREATED BY SELLER)
OR CORRECT ANY MATTER SHOWN ON A SURVEY OF THE PROPERTY. IN THE EVENT BUYER
SEEKS SPECIFIC PERFORMANCE AND IS UNSUCCESSFUL IN OBTAINING SPECIFIC
PERFORMANCE, BUYER SHALL BE ENTITLED TO TERMINATE THIS AGREEMENT AND RECOVER THE
DEPOSIT. BUYER SHALL BE DEEMED TO HAVE ELECTED TO TERMINATE THIS AGREEMENT IF
BUYER FAILS TO DELIVER TO SELLER WRITTEN NOTICE OF ITS INTENT TO ASSERT A CAUSE
OF ACTION FOR SPECIFIC PERFORMANCE WITHIN THIRTY (30) DAYS FOLLOWING THE
SCHEDULED CLOSING DATE OR, HAVING GIVEN SUCH NOTICE, FAILS TO FILE A LAWSUIT
ASSERTING SUCH CAUSE OF ACTION IN THE PROPER COURT WITHIN SIXTY (60) DAYS
FOLLOWING THE SCHEDULED CLOSING DATE. THE PARTIES WITNESS THEIR AGREEMENT TO
THIS LIQUIDATED DAMAGES PROVISION AND THIS LIMITATION OF REMEDIES PROVISION BY
THEIR EXECUTION BELOW:
BUYER: NETWORK APPLIANCE, INC.
a Delaware Corporation
By: /s/ CHRIS CARLTON
Its: Vice President
SELLER: 495 Java Drive Associates, L.P.
a California Limited Partnership
By M-D Venture, Inc.,
a California Corporation,
its general partner
By: /s/ STEVE DOSTART
Steve Dostart, Vice President
(c) Cure Period for Default. Prior to termination of this
Agreement by either party for default, the party alleging default shall give the
defaulting party written notice thereof, and the defaulting party shall have ten
(10) days from receipt of such notice to cure such default.
4. Purchase Price. Buyer shall pay Seller a purchase price
("Purchase Price") for the Property of Thirty-Three Million Seven Hundred Fifty
Thousand Dollars ($33,750,000.00), payable at the Close of Escrow, as follows:
(a) Application of the Deposit; and
(b) Paying the remainder in cash ("Cash Payment").
The Purchase Price shall be subject to adjustment pursuant to Section 6 below.
5. Conditions Precedent. At or before Close of Escrow the
following conditions precedent ("Conditions Precedent") shall be either
satisfied or waived by Buyer as a condition to Buyer's obligation to proceed
with the purchase of the Property:
(a) Title. The term "Conditions of Title" shall refer to
those exceptions to title (including, without limitation, Title Company's
standard printed exceptions to title with respect to an ALTA Owner's Extended
Form policy of title insurance (an "ALTA Policy") listed on EXHIBIT C
incorporated herein by reference, the lien for real property taxes not
delinquent, any current assessments (subject to Seller's obligation to pay
delinquent assessments or credit same to the Purchase Price at closing), the
effect of the Lot Line Adjustment and the CC&R's and any other encumbrances or
matters of title caused or approved in writing by Buyer. On the Closing Date,
Title Company shall be unconditionally committed to issue (a) an American Land
Title Association ("ALTA") Extended Title Policy Form B (1970) for the Property
("ALTA Title Policy"), with a liability limit in the amount of the Purchase
Price and insuring fee title vested in Buyer, and (b) endorsements to the ALTA
Title Policy (i) to provide Buyer with assurance that the Property is the same
as shown on the Survey, (ii) to
provide Buyer with assurance that the Property is contiguous with the property
known as 475 Java Drive, and (iii) such other endorsements as Buyer may
reasonably request, including without limitation zoning, tax parcel, access, and
owner's comprehensive (ALTA 100, modified for owner, or equivalent) endorsements
(collectively, the "Endorsements"); provided, however, the availability of such
Endorsements shall not be a Condition Precedent to Buyer's obligation hereunder.
Buyer shall take title to the Property subject to the Conditions of Title.
(b) Survey. Buyer has approved a certified ALTA survey of
the Property prepared by Kier & Wright dated April 15, 1998 ("Survey"). Any
revisions (including certification to Buyer) to the ALTA survey previously
provided to Buyer by Seller which are requested by Buyer shall be at Buyer's
sole cost and expense. At Close of Escrow Seller shall deliver to Buyer the
(c) Property Documents. Buyer has reviewed and approved
all of the reports listed on EXHIBIT D attached hereto and incorporation herein
("Property Documents"). As of the Close of Escrow there shall have been no
material adverse change in the physical condition of the Property as described
in the Property Documents which would materially, adversely affect Buyer's use
and occupancy of the Property and Seller shall deliver to Buyer its certificate
representing and warranting that (except as described in such certificate) (i)
there has been no such material adverse change in such physical condition
between the Execution Date and the Close of Escrow, (ii) all Improvements
completed by Seller prior to the Closing Date have been built in accordance with
the Seller Plans and in compliance with all applicable laws and the CC&Rs, (iii)
all asbestos containing building materials contained in the improvements located
on the Land as of the date the Land was acquired by the Seller have been removed
and transported to a suitable disposal site, in compliance with law and any
contracts concerning the removal, transportation, or disposal of asbestos
located at or on the Land had been fully performed as of the Closing Date and
(iv) there are no agreements which would be binding upon the Property or the
Buyer following Close of Escrow except as expressly contemplated by this
Agreement. ("Seller's Closing Certificate").
(d) Completion of Improvements. Seller shall have
substantially completed the Improvements in accordance with the Work Letter.
(e) Seller's Performance. Seller shall have performed all
of its obligations under this Agreement.
6. Completion of Improvements.
(a) Completion of Improvements. Seller shall be obligated
to complete the Improvements in accordance with the Work Letter.
(b) Milestones. The parties have set forth certain events
which must occur prior to or during construction of the Improvements (each, a
"Milestone"), which must be accomplished by Seller on or before certain
prescribed dates or Buyer shall have the right to terminate this Agreement and
pursue certain remedies described in Section 6(e) below. The Milestones to which
Buyer and Seller have agreed are as follows:
(1) Construction of the foundation for the building (included
within the Improvements) shall have commenced no later than
June 10, 1998; and
(2) The Improvements shall have been substantially completed
(as defined in the Work Letter) in accordance with Seller's
Plans, except for landscaping, on or before June 17, 1999.
The Milestone dates set forth above shall be extended as follows: (A) One day
for each day of delay caused by Buyer Delays (as defined in the Work Letter),
(B) One day for each day of Force Majeure Events (as defined in the Work
Letter), however, the maximum number of days that any such Milestone can be
extended for such Force Majeure Delays shall be limited to a total of sixty (60)
days except that no such limit shall apply in the event Seller's Plans are
changed in response to a request by Buyer under circumstances where Seller has
informed Buyer in writing that Seller believes such change is material and would
not be acceptable to Seller if Seller were building the Improvements on a
speculative basis rather than for Buyer, and (C)
By the amount of time required to complete any arbitration process
resulting from disputes between Seller and Buyer arising prior to the Milestone,
to the extent the arbitration process (and the issue being arbitrated) actually
causes a delay in achieving such Milestones. The aggregate extension of the
Milestone dates provided for herein shall be referred to as the "Milestone
Extension Period". The parties acknowledge that Seller has satisfied the
Milestone set forth in clause (i) above.
(c) Changes requested by Buyer. Buyer has reviewed and
approved the Seller Plans (as defined in the Work Letter) for construction of
the Improvements. Buyer shall have the right to submit written requests for
changes to the existing plans for the Improvements which changes shall be
subject to Seller's written consent. Seller shall not unreasonably withhold it's
consent to such changes so long as (i) such changes do not extend the time
period for substantial completion of the Improvements by more than ninety (90)
days as reasonably determined by Seller (Buyer acknowledges that the date
contemplated for substantial completion of the Improvements as of the date
hereof without giving effect to any Milestone Extension Period or any requests
by Buyer hereunder is March 17, 1999), and (ii) Buyer approves in writing
Seller's estimated adjustment to the Purchase Price caused by such changes.
(d) Adjustment to Purchase Price.
(1) If any changes requested by Buyer and approved by
Seller pursuant to this Section 6 increase or decrease the cost of constructing
the Improvements the Purchase Price shall be adjusted accordingly. Such costs
shall include but not be limited to Seller's carrying costs (including real
property taxes, cost of financing on all costs associated with the Property at a
rate of Comerica Bank's Prime Rate plus 1%, etc.) and hard and soft costs;
provided, however, such costs shall not include any mark-up charged by Seller.
(2) In the event that the Close of Escrow occurs
prior to completion of the Improvements, Seller shall be obligated to complete
the Improvements following Close of Escrow. In such event the Purchase Price
shall be reduced by the Interest Savings. The "Interest Savings" shall mean the
amount of interest that Seller would have paid to Comerica Bank between the
Closing Date and the date estimated (as of the closing date) for
substantial completion of the Improvements based upon the loan balance as of the
Closing Date and Seller's best available interest rate pursuant to its loan from
Comerica Bank. Buyer and Seller shall execute such additional documents and
instruments as may be necessary to accomplish the purposes of this
sub-paragraph, including but limited to, an agreement allowing Seller access to
the Property for the purposes of completion of the Improvements, appropriate
requirements for insurance to be carried by Buyer as owner of the Property, etc.
(e) Right to Terminate. If any Milestone set forth in
Section 6(b) is not achieved by Seller, Buyer shall have the right to terminate
this Agreement by written notice to Seller at any time within ten (10) business
days after Seller's failure to achieve the particular Milestone; provided,
however, if the conditions described in Section 6(f) are met Buyer shall have
the right to elect the remedies described in Section 6(f). If Buyer exercises
its termination right, Buyer shall be entitled to the remedies provided in this
Section 6(e), which shall be Buyer's sole and exclusive remedies with respect to
Seller's failure to achieve any Milestone. If Buyer exercises a termination
right pursuant to this Section 6(e) and Seller believes that the Milestone was
achieved by the appropriate date (as extended by the Milestone Extension
Period), the parties agree to submit the dispute concerning Seller's failure to
achieve that particular Milestone, and Buyer's resulting right to terminate the
Lease, to binding arbitration pursuant to the provisions of Section 16.
Notwithstanding any other provision of this Agreement or the Work Letter, if
Seller fails to achieve any Milestone Buyer's sole and exclusive remedies shall
be to either (i) elect to proceed under Section 6(f) if the conditions set forth
therein have occurred, or (ii) terminate this Agreement and receive the Deposit
and damages from Seller (which shall be paid within thirty (30) days of the date
of Buyer's notice of termination, or, if the parties resort to arbitration
pursuant to the provision set forth above, then within thirty (30) days of
Buyer's prevailing on said termination in arbitration) in the following amounts
(all clauses referenced are in Paragraph 6(b)): $250,000, as liquidated damages
for failure of Seller to achieve the Milestone described in clause (1); and
$500,000, as liquidated damages for failure of Seller to achieve the Milestone
described in clause (2). Seller and Buyer acknowledge and agree that if Seller
fails to achieve the Milestone described in clause (1) or (2) and Buyer elects
to terminate this Agreement pursuant to this paragraph as a result thereof, the
damages which Buyer will suffer are difficult, if not impossible to calculate,
and that the above-described liquidated damages are a fair and reasonable
estimate of the damages that Buyer would suffer with respect to a failure to
achieve the Milestone described in clause (1) or (2).
(f) Buyer's Self Help Remedy. Notwithstanding the above,
in the event that all of the following are true: (i) Seller has failed to
achieve a Milestone set forth in Section 6(b), and (ii) Buyer is not in a
continuing default under this Agreement, then Buyer shall have the right to
substantially complete the Improvements and offset its actual out of pocket
costs and expenses incurred in connection therewith against the Purchase Price.
7. No Incumbrance or Transfer. Except as provided herein, Seller shall
not incumber, lease, transfer, assign or sell all or any portion, or interest
in, the Property, or enter into any agreement or contract effecting or relating
to the Property without Buyer's prior written consent, which consent may be
withheld in Buyer's sole discretion. Seller shall be entitled to encumber the
Property for the purpose of securing one or more construction loans. Seller may
also implement the Lot Line Adjustment, record the CC&R's and execute such other
contracts (but not contracts or encumbrances that will be binding upon Buyer or
the Property after the
Close of Escrow) as may be necessary or advisable in connection with performing
its obligations hereunder including completion of the Improvements.
(a) Escrow. Within two (2) Business Days of the Execution Date, Seller
shall establish an escrow ("Escrow") with the Escrow Agent for the close of this
transaction. An executed copy of this Agreement shall be deposited with the
Escrow Agent by Buyer and this Agreement, together with Seller's Additional
Escrow Instructions (as hereinafter defined), if any, and Buyer's Additional
Escrow Instructions (as hereinafter defined), if any, shall constitute Escrow
Agent's escrow instructions for closing Escrow. Escrow shall close ("Close of
Escrow") on or before the Closing Date.
(b) Seller. On or prior to the Closing Date Seller shall deposit the
following into Escrow:
(i) Grant Deed. A duly executed and acknowledged Grant
Deed in usual form setting forth all exceptions to title created or suffered by
Seller which are not to be removed at or prior to Closing;
(ii) Non-Foreign Person Certificates. Duly executed
non-foreign person certificates ("Non-Foreign Person Certificates") in usual
form sufficient to relieve Buyer of any withholding requirements pursuant to the
provisions of Section 1445 of the Internal Revenue Code of 1986 as amended (the
"Code") and Section 18805 of the California Revenue and Taxation Code and a
California Form 590-RE certifying that Seller has a permanent place of business
or is qualified to do business in the State of California;
(iii) Assignment of Intangible Property. An assignment, in
a form reasonably approved by Buyer and Seller, of all Seller's rights, title,
and interest to any and all plans, permits, approvals, entitlements and other
intangible property relating to the Property (the "Assignment of Intangibles");
(iv) Assignment of Warranties. An assignment by Seller, in
a form reasonably approved by Buyer and Seller, of all Seller's rights, title
and interest under the Warranties (the "Assignment of Warranties");
(v) Closing Certificate. Seller's Closing Certificate, in
a form reasonably approved by Buyer and Seller; and
(vi) Additional Escrow Instructions and Documents. Such
additional escrow instructions ("Seller's Additional Escrow Instructions") and
documents as Escrow Agent may reasonably require of Seller to close the sale of
the Property in accordance with this Agreement, which instructions shall not be
inconsistent with the terms of this Agreement.
(c) Buyer. On or prior to the Closing Date Buyer shall deposit the
following into Escrow:
(i) Cash Payment. The Cash Payment;
(ii) Additional Cash. Additional cash in the amount
necessary to pay Buyer's share of closing costs and prorations, as hereinafter
(iii) Release and Assumption. The Release and Assumption
provided for in Section 11(g); and
(iv) Additional Escrow Instructions and Documents. Such
additional escrow instructions ("Buyer's Additional Escrow Instructions") and
documents as Escrow Agent may reasonably require of Buyer to close the sale of
the Property in accordance with this Agreement.
9. Close of Escrow.
(a) Time. When the Escrow Holder has confirmed that Title Company is in
a position to issue an ALTA Extended Policy (Form B-1970) insuring title to the
Property as being vested in Buyer in accordance with Section 5(a) and all
documents and funds required hereby have been deposited with Escrow Agent,
Escrow Agent shall cause Close of Escrow to occur as provided below.
(b) Procedure. Escrow Agent shall close Escrow as follows:
(i) Record the following documents in the order set forth
(1) The Grant Deed.
(ii) Deliver to Seller the following:
(1) The Cash Payment and the Deposit;
(2) The Release and Assumption; and
(3) A conformed copy of the Grant Deed.
(iii) Deliver to Buyer the following:
(1) An ALTA Policy in accordance with
(2) The Non-Foreign Person Certificates; and
(3) Conformed copies of the Grant Deed,
Assignment of Warranties, Seller's Closing Certificates and Assignment of
Intangibles, and the originals of such documents following their recordation.
(c) Closing Costs and Prorations.
(i) Closing Costs. Seller shall pay the cost for a basic
CLTA owner's policy; Buyer shall pay all additional costs for the Title Policy
and all Endorsements. Seller shall pay county transfer taxes and one-half of the
escrow fees applicable to the sale. Buyer shall pay one-half of the escrow fees
and all recording fees attributable to the conveyance documents, and Seller
shall pay recording fees attributable to the release of any liens on the
Property. All other costs and charges of the escrow for the sale shall be paid
in accordance with custom.
(ii) Prorations. Real estate taxes and all other expenses
normal to the operation and maintenance of the Property, shall be prorated as of
12:01 a.m. on the Closing Date.
(iii) Escrow Cancellation Costs. Notwithstanding the
provisions of subsection (i) above, if Escrow fails to close due to Seller's
default, Seller shall pay all Escrow cancellation charges. If Escrow fails to
close due to Buyer's default, Buyer shall pay all Escrow cancellation charges.
If Escrow fails to close for any reason other than the foregoing, Buyer and
Seller shall each pay one-half (1/2) of any Escrow cancellation charges. "Escrow
cancellation charges" means all fees, charges, and expenses incurred by Escrow
Agent, including all expenses incurred in connection with issuance of the
Preliminary Report and other title matters.
10. Brokers. Each of Buyer and Seller represents to the other party
that, other than Cornish & Carey representing Buyer and CPS, representing Seller
("Brokers"), such party has not engaged any broker or finder in connection with
any of the transactions contemplated by this Agreement. Buyer shall indemnify,
defend and hold Seller harmless from and against any loss, cost or expense,
including, but not limited to, attorneys' fees and court costs, resulting from
any claim against Seller for any fee or commission by any broker or finder
claiming by or through Buyer, other than the Brokers. Seller shall indemnify,
defend and hold Buyer harmless from and against any loss, cost or expense,
including, but not limited to, attorneys' fees and court costs, resulting from
any claim for a fee or commission by any broker or finder claiming by or through
Seller. Seller shall be responsible for the payment of any fees or commissions
payable to the Brokers in connection with the transaction contemplated by this
Agreement in accordance with Seller's written agreements with such brokers. The
covenants contained herein shall survive the Close of Escrow.
11. Seller's Representations, Warranties and Covenants.
(a) Seller's Representations and Warranties. Seller hereby makes the
following representations and warranties to Buyer which representations and
warranties shall survive the Close of Escrow for a period of twelve (12) months
(at which time these representations and warranties shall expire):
(i) Litigation; Government Action. Except as disclosed to
Buyer in writing, there is no claim, litigation, notice that the Property is in
violation of law, or governmental investigation presently pending with respect
to which Seller has been served with process or other notice thereof or, to the
best of Seller's knowledge, otherwise pending or threatened, against or relating
to the Property.
(ii) Condemnation. There is presently no pending
condemnation of the Property or any part thereof with respect to which Seller
has been served with process or other notice thereof nor, to the best of
Seller's knowledge, is any such condemnation otherwise pending or contemplated.
(iii) Leases. There are no leases or other occupancy
agreements relating to the Property.
(iv) Hazardous Materials.
(1) For purposes hereof, "Hazardous
Materials" shall mean any and all asbestos, radioactive material, hazardous
waste, toxic substance or related material, including but not limited to those
materials and substances defined as "hazardous substances", "hazardous
materials", "hazardous wastes" or "toxic substances" in any California or
federal law or regulation.
(2) Seller has not released or discharged,
or caused to be released or discharged, upon the Property any Hazardous
Materials, and to the best of Seller's knowledge, except as disclosed in the
Property Documents, there are no Hazardous Materials present on, in, or under
(3) To the best of Seller's knowledge, the
Property Documents are all of the documents and reports in Seller's possession
pertaining to Hazardous Materials on or at the Property.
(v) Property Documents. There are no other documents or
reports in Seller's possession or under Seller's control other than the Property
Documents, describing the condition of the Property concerning the presence of
Hazardous Materials, the geotechnical condition of the soils or other like
physical condition of the Property as of the Execution Date; provided, however,
the improvements demolished and removed by Seller contained asbestos. Seller
acknowledges and agrees that the demolition and removal of the existing
improvements including the asbestos containing materials therein and all costs
in connection therewith is the sole responsibility of Seller.
(b) Organization and Authority. Seller is a California limited
partnership validly existing and in good standing under the laws of California.
Seller and has full power to enter into this Agreement and is duly qualified to
transact business in California. The execution, delivery, and performance of
this Agreement have been duly authorized and approved by all requisite action
and the consummation of the transactions contemplated hereby will be duly
authorized and approved by all requisite action of Seller and no other
authorizations or approvals, whether of governmental bodies or otherwise, will
be necessary in order to enable Seller enter into or to comply with the terms of
(c) Binding Effect of Documents. This Agreement and the other documents
to be executed by Seller hereunder, upon execution and delivery thereof by
Seller, will have been duly entered into by Seller, and will constitute legal,
valid and binding obligations of Seller. Neither this Agreement nor anything
provided to be done under this Agreement
violates or shall violate any contract, document, understanding, agreement, or
instrument to which Seller is a party or by which it is bound.
(d) "Best Knowledge" Definition. For purposes of this Section 11, the
term "to the best of Seller's knowledge" shall mean the current actual knowledge
of John Mozart and Steve Dostart after usual inquiry in connection with the
operation of the Property. Seller represents that John Mozart and Steve Dostart
are the representatives of Seller with supervisory responsibilities concerning
the Property who would, in the ordinary course of their responsibilities,
receive notice from persons or entities of any of the matters described in the
representations and warranties in this Section 11.
(e) "As-Is" Condition; Release and Assumption. If Seller breaches any
representation, warranty, or covenant hereunder prior to Closing and Buyer
closes escrow with knowledge thereof, Buyer shall be deemed to waive such
breach. Except as expressly provided in this Agreement and in Seller's Closing
Certificate, Seller makes no representations or warranties of any kind, express
or implied, written or oral, as to the physical condition of the Property; the
uses of the Property or any limitations thereon, including, without limitation,
zoning, environmental or other laws, regulations or governmental requirements;
the utilities or other physical equipment and fixtures on the Property, the
costs of operating the Property or any other aspect of the economic operations
on the Property; the possibility of future assessments of charges being levied
against the Property or imposed as a condition to development or construction;
or the condition of the soils or groundwater of the Property. Except as provided
herein, Buyer specifically acknowledges that it is acquiring the Property in an
"as-is" condition (as such term is most broadly construed), in reliance upon its
own inspection and investigation of the Property. Except as expressly provided
herein, Seller makes no representation or warranties with respect to the
condition of title to the Property, and Buyer agrees that it will rely solely on
its policy of title insurance. At closing, and as a condition to Seller's
obligations hereunder, Buyer shall, pursuant to a form of Release and Assumption
("Release and Assumption") prepared by Seller and delivered to Buyer for
approval by Buyer within ten (10) days after the Execution Date, (1) release
Seller from any and all claims, liability or causes of action (except for the
express representations and warranties herein and in Seller's Closing
Certificate to the extent the same survive closing) in connection with the
Property and (2) assume all of Seller's obligations under any and all laws and
regulations pertaining to the Property (except (i) those occurring prior to the
Close of Escrow, or (ii) for Seller's obligations in connection with completion
of the Improvements, if the Improvements are not completed as of the Closing
12. Loss by Fire or Other Casualty; Condemnation.
(a) Condemnation and General Casualty. Buyer shall be
bound to purchase the Property for the full Purchase Price as required by the
terms hereof, without regard to the occurrence or effect of any damage to or
destruction of any improvements or condemnation of any portion of the Property.
In the event of a casualty Buyer may elect to purchase the Property pursuant to
the terms of this sub-paragraph (a) or to require Seller to repair and complete
the Improvements pursuant to sub-paragraph (c). Such election shall be made by
written notice given within thirty (30) days following the casualty. If Buyer
elects to proceed pursuant to this sub-paragraph (a), the Purchase Price shall
be credited by the amount of any insurance proceeds or condemnation awards
(excluding proceeds or awards payable in respect of
carrying costs or other costs born by Seller and not subject to adjustment of
the Purchase Price as provided herein) collected by Seller as a result of any
such damage or destruction or condemnation less any monies actually expended by
Seller to repair any damage, plus any deductible amounts attributable to such
damage or destruction, or such proceeds shall be assigned to Buyer if not then
(b) Seller Cooperation. If Seller assigns the proceeds of
any insurance policy to Buyer pursuant to Section 12(a), Seller shall cooperate
with Buyer in presenting and prosecuting the claim with Seller's insurance
carriers, shall follow Buyer's instructions with respect thereto (except to the
extent Seller is advised by counsel that following a particular instruction
would expose Seller to liability, or to the extent Seller would incur additional
cost to follow such instruction which is not paid by Buyer), and will not settle
any such claim without Buyer's written approval.
(c) Insurance. Seller shall purchase and keep in force a
policy or policies of fire and property damage insurance (including coverage for
flood and earthquake, if available) covering loss or damage to the Property
(including the improvements) in the amount of the full replacement value thereof
including comprehensive builder's risk/course of construction insurance. In the
event of a casualty and election by Buyer (pursuant to sub-paragraph (a) above)
to require Seller to repair and complete the Improvements, Seller shall be
obligated to repair and complete the Improvements pursuant to the terms and
conditions hereof subject to extension of all of the dates for performance and
the closing date for the delay caused by the casualty. In such event there shall
be no adjustment to the Purchase Price for increase costs sustained by Seller
(whether or not such costs are covered by insurance) in connection with or
caused by the casualty. Notwithstanding anything to the contrary herein, in the
event of a casualty under circumstances where the cost of completion of the
Improvements exceeds the Available Funds by an amount in excess of $1,000,000,
Seller may terminate this agreement unless Buyer elects to pay such excess. The
term "Available Funds" shall mean the sum of (i) insurance proceeds, (ii)
deductibles in respect of the casualty loss and (iii) the amount of the cost of
the Improvements which Buyer had not yet disbursed (and for which Buyer had not
incurred liability) as of the date of the casualty.
13. Successors and Assigns. The terms, covenants, and conditions herein
contained shall be binding upon and inure to the benefit of the successors and
assigns of the parties hereto. Buyer may assign it's rights under this Agreement
to a financing entity in connection with a synthetic lease transaction without
the need for Seller's prior written consent but no such assignment shall relieve
the assignor from primary liability for its obligations hereunder. Prior to the
acquisition of the Property, Buyer intends to assign Buyer's interest under this
Agreement to an entity (the "Lessor"), who will then lease all of the acquired
portions of the property to Buyer, as tenant ("Tenant"), pursuant to a synthetic
lease ("Lease") to be executed by Lessor and Tenant, pursuant to which Tenant
shall have the right to construct certain improvements thereon, pursuant to
plans and specifications approved by Lessor and Tenant. The parties acknowledge
that (a) Tenant is intended to be the ultimate occupant and user of the Real
Property, and (b) the improvements to be constructed thereon are being designed
for Tenant's benefit and to Tenant's specifications. Therefore, the parties
acknowledge that Tenant is an intended third party beneficiary of all of
Seller's covenant, representations, warranties and obligations under this
14. Entire Agreement. This Agreement contains all of the covenants,
conditions and agreements between the parties and shall supersede all prior
correspondence, agreements, and understandings, both oral and written. No
provisions of this Agreement may be amended or modified in any manner except by
an agreement in writing duly executed by the parties hereto.
15. Governing Law. This Agreement shall be governed by and construed in
accordance with the laws of the State of California as applied to agreements
among California residents which are entered into and performed entirely within
16. Attorneys' Fees; Arbitration.
(a) Attorneys' Fees. In the event of any litigation or
arbitration regarding the rights and obligations under this Agreement, the
prevailing party shall be entitled to recover, in addition to damages,
injunctive or other relief, reasonable attorneys' fees expert witness fees, and
(b) Arbitration of Disputes. ANY CONTROVERSY OR CLAIM
ARISING OUT OF THIS AGREEMENT SHALL BE SETTLED BY ARBITRATION IN ACCORDANCE WITH
THE RULES OF THE AMERICAN ARBITRATION ASSOCIATION FOR THE ARBITRATION OF
COMMERCIAL DISPUTES, AND JUDGMENT ON THE AWARD RENDERED BY THE ARBITRATOR(S) MAY
BE ENTERED IN ANY COURT HAVING JURISDICTION. THE PREVAILING PARTY IN SUCH
ARBITRATION SHALL BE ENTITLED TO ATTORNEYS' FEES AND COSTS.
NOTICE: BY INITIALING IN THE SPACE BELOW YOU ARE AGREEING TO
HAVE ANY DISPUTE ARISING OUT OF THE MATTERS INCLUDED IN THE "ARBITRATION OF
DISPUTES" PROVISION DECIDED BY NEUTRAL ARBITRATION AS PROVIDED BY CALIFORNIA LAW
AND YOU ARE GIVING UP ANY RIGHTS YOU MIGHT POSSESS TO HAVE THE DISPUTE LITIGATED
IN A COURT OR JURY TRIAL. BY INITIALING IN THE SPACE BELOW YOU ARE GIVING UP
YOUR JUDICIAL RIGHTS TO DISCOVERY AND APPEAL, UNLESS THOSE RIGHTS ARE
SPECIFICALLY INCLUDED IN THE "ARBITRATION OF DISPUTES" PROVISION. IF YOU REFUSE
TO SUBMIT TO ARBITRATION AFTER AGREEING TO THIS PROVISION, YOU MAY BE COMPELLED
TO ARBITRATE UNDER THE AUTHORITY OF THE CALIFORNIA CODE OF CIVIL PROCEDURE. YOUR
AGREEMENT TO THIS ARBITRATION PROVISION IS VOLUNTARY.
WE HAVE READ AND UNDERSTAND THE FOREGOING AND AGREE TO SUBMIT
DISPUTES ARISING OUT OF THIS AGREEMENT TO NEUTRAL ARBITRATION.
CONSENT TO NEUTRAL ARBITRATION BY:
______________ (SELLER): __________________(BUYER).
17. Notices. All notices required or permitted to be given pursuant to
the terms hereof shall be in writing and either delivered by hand delivery,
professional courier service
which provides written evidence of delivery or deposited in the United States
mail, registered or certified, postage prepaid and addressed as follows:
To Seller: 495 Java Drive Associates, L.P.
c/o Mozart Development Company
1068 East Meadow Circle
Palo Alto, California 94303
Attn: John Mozart and Steve Dostart
Tel. (415) 493-9000
FAX (415) 493-9050
With a copy to: Ellman, Burke, Hoffman & Johnson
One Ecker Building, Suite 200
San Francisco, California 94105
Attn: Jeffrey W. Johnson, Esq.
Tel. (415) 777-2727
FAX (415) 495-7587
To Buyer: Network Appliance Inc.
2770 San Tomas Expressway
Santa Clara, California 95051
Attn: Chris Carlton
Tel. (408) 367-3200
FAX (408) 367-3151
With a copy to: Network Appliance Inc.
2770 San tomas Expressway
Santa Clara, California 95051
Attn: Fran Bellet, Esq.
Tel. (408) 367-3200
FAX (408) 367-3151
The foregoing addresses may be changed by written notice to the other party as
provided herein. Notices shall be deemed delivered and received, in the case of
personal delivery or delivery by courier as aforesaid, on the day physically
delivered to the indicated addressee, and in the case of delivery by United
States mail, three (3) Business Days after deposit in the United States mail as
18. Exhibits. All exhibits are attached hereto and incorporated herein
by this reference.
19. Authority. Each person executing this Agreement on behalf of a
party to this Agreement hereby represents and warrants that he or she has
authority to execute this Agreement on behalf of such party.
20. Headings. Headings at the beginning of any paragraph or Section of
this Agreement are solely for the convenience of the parties and are not a part
of this Agreement or to be used in the interpretation hereof.
21. Survival. The representations, warranties and covenants of the
parties hereto shall survive the Close of Escrow, or the termination of the
Agreement if the Close of Escrow does not occur, subject to the express
limitations on survivability contained in this Agreement.
22. Waiver. No waiver by Buyer or Seller of a breach of any of the
terms, covenants, or conditions of this Agreement by the other party shall be
construed or held to be a waiver of any succeeding or preceding breach of the
same or any other term, covenant or condition herein contained. No waiver of any
default by Buyer or Seller hereunder shall be implied from any omission by the
other party to take any action on account of such default if such default
persists or is repeated, and no express waiver shall affect a default other than
as specified in such waiver. The consent or approval by Buyer or Seller to or of
any act by the other party requiring the consent or approval of the first party
shall not be deemed to waive or render unnecessary such party's consent or
approval to or of any subsequent similar acts by the other party.
23. Confidentiality. Buyer and Seller shall both maintain this
Agreement in the terms and conditions of confidence except as required by law
and except as required in connection with the performance of each of the
obligations of Buyer and Seller hereunder. Notwithstanding anything to the
contrary herein, the provisions of this Section 23 shall be separate and
severable from all of the other provisions of this Agreement. A breach or
alleged breach of the provisions of this Section 23 shall not be grounds for
termination of this Agreement or otherwise excuse the performance of any other
obligations hereunder. The maximum damages recoverable for a breach of the terms
of this Section 23 shall be Twenty-Five Thousand Dollars ($25,000.00).
24. Withdrawal from Market. During the period that this Agreement is in
effect Seller shall withdraw the Property from the market and shall not except
any back-up offers for the sell or lease of all or any portion of the Property.
25. Severability. If any phrase, clause, sentence, paragraph, section,
article, or other portion of this Agreement shall become illegal, null or void
or against public policy, for any reason, or shall be held by any court of
competent jurisdiction to be illegal, null or void or against public policy, the
remaining portions of this Agreement shall not be affected thereby and shall
remain in force and effect to the fullest extent permissible by law. Buyer and
Seller acknowledge and agree that Buyer and Seller have simultaneously executed
a Lease and an Option Agreement for the property adjoining the Property at 475
Java Drive ("Separate Transaction"). The parties agree that for all purposes
hereunder the Separate Transaction is separate and independent of any and all
rights and obligations of the parties hereunder.
26. Counterparts. This Agreement may be executed in any number of
counterparts, each of which shall be deemed an original, and all of which
together shall constitute one and the same instrument.
IN WITNESS WHEREOF, the parties hereto have executed this Agreement as
of the dates set forth next to their respective signatures below.
BUYER: Network Appliance, Inc.,
a Delaware corporation
By: /s/ CHRIS CARLTON
Its: Vice President
495 Java Drive Associates, L.P.
a California Limited Partnership
By M-D Venture, Inc.,
a California Corporation,
its general partner
By: /s/ STEVE DOSTART
Steve Dostart, Vice President
[Description of Property]
MAP OF PROJECT (INCLUDING BUILDING)
[SITE PLAN WITH BUILDING OUTLINED AND CROSSHATCHED]
DESCRIPTION OF LAND
[PARCEL MAP AND LEGAL DESCRIPTION HERE FROM TITLE REPORT]
[FORM OF CC&Rs TO BE ATTACHED]
1. Obligations of Seller and Buyer. Seller shall furnish and
install the Improvements provided for in Paragraph 2 below at Seller's expense.
The quantities, character and manner of installation of all of the foregoing
work shall be subject to the limitations imposed by any applicable regulations,
laws, ordinances, codes and rules.
2. Improvements. Seller shall furnish an industrial shell
building which exterior and site shall substantially comply with the, "Base
Building Improvement Plans" described on Schedule 1 hereto, excepting that the
sitework shall be revised to be in substantial conformance with the site plan
defined in Schedule 2 hereto and excepting those items included on the Base
Building Improvement Plans for informational purposes only (eg. restroom
locations, shaft locations, elevators, extra stairwells, etc.) noted on the
plans as N.I.C. and as further specified below
("Improvements"). However, in the event of a conflict between the (a) Base
Building Improvement Plans and (b) the items listed in (i) through (viii) below
and the Exclusions listed in Paragraph 3, then the latter shall control.
(i) floor - hard trowel, smooth concrete, level (at a
specification not to exceed a slope of 1/8" in 10 feet) and ready for
installation of floor covering (excluding standard floor preparation and
waterproofing); underslab waterproofing shall include 2" sand layer over gravel
with visqueen vapor barrier ;
(ii) ceiling/roof - (a) structural steel members, (b) exposed
corrugated metal deck, (c) building sprinkler system to include main floor shut
off valves, primary loop;
(iii) exterior walls - (a) exposed metal studs and/or aluminum
window system members, empty framing cavity, and the backside of exterior
sheeting and fireproofed columns (if required by code), (b) completed window
assembly with painted metal window frames;
(iv) electrical/utilities - small electrical transformer for
site lighting, all other utilities (including telephone lines and sanitary
sewer) stubbed into shell, and conduit (excluding cabling) installed to the 475
Java Drive property line 495 Java Drive;
(v) elevator - two (2) elevator pits;
(vi) stairs - one (1) building staircase (minimal level
required to obtain shell building permit);
(vii) live load - slab and upper floor decks shall be designed
to support a live load of eighty (80) pounds per square foot and a partition
load of twenty (20) pounds per square foot for a total of one hundred (100)
pounds per square foot;
(viii) site work - parking, parking lot lighting (in
compliance with applicable code requirements) striping, curb cuts, ramps,
sidewalks (if required by the City of Sunnyvale),
underground storm drains, and main entries to the Building to be in compliance
with the applicable ADA requirements;
(ix) roof screens - roof screens as noted on the Base Building
3. Exclusions from Base Building Improvements. Specific
exclusions from Improvements include, but are not limited to, (a) sprinklers
beyond those required for shell permit, (b) window coverings, (c) fire alarms or
security systems, (d) interior walls, (e) HVAC systems, (f) electrical service
in the Building, (g) restrooms, (h) elevator, (i) lobby, (j) electrical,
telephone, janitorial and similar closets, (k) building cabling, (l) building
signage, (m) insulation.
4. Seller's Plans. Seller shall provide Buyer with necessary
base "design build" drawings, specifications, and CAD diskettes (to the extent
available) for the Buildings no later than July 1, 1998 ("Seller's Plans").
Seller's Plans shall be substantially in accordance with the plans described on
Schedule 1 (which have been approved by Buyer), together with and including the
specifications described for the Improvements in Paragraph 2 of this Work
Letter, but shall specifically exclude any improvements to the interior of the
Building, or items noted in Paragraph 3 as specific exclusions from the
Improvements. Seller shall have the right to change Seller's Plans after
submission to Buyer as needed to satisfy any requirements of the City of
Sunnyvale; provided, however, Seller shall provide Buyer prior written notice of
any such changes and notice of meetings with the City of Sunnyvale to be
attended by Buyer, which Seller shall be entitled to attend. Any additional time
required to accommodate Buyer's involvement in such meetings shall constitute a
Buyer Delay pursuant to Section 7 below to the extent it actually delays
Excepting changes required by the City of Sunnyvale, any
changes in Seller's Plans initiated by Seller shall be subject to Buyer's review
and approval, which shall not be unreasonably withheld, conditioned or delayed.
Buyer must notify Seller in writing of any disapproval with respect to any
submitted plans and specification within three (3) business days, unless the
revisions include new detailed mechanical, electrical and plumbing drawings or
substantial revisions thereto, in which case, Buyer shall have five (5) business
days to notify Seller in writing of any disapproval or unless the plans and
specifications are the final complete set of plans and specifications which
Seller intends to submit to the applicable authorities to obtain its building
permit and other applicable governmental licenses, in which case Buyer shall
have seven (7) business days to notify Seller in writing of any disapproval. Any
written notice containing Buyer's disapproval, shall also include the specific
reasons for disapproval. If Buyer fails to notify Seller of any disapproval
within the applicable time periods provided above, Buyer shall be deemed to have
approved the submitted revised plans and specifications.
5. Change Orders. Any changes requested by Buyer that
necessitate revisions or changes in Seller's Plans or the design or construction
of the Improvements or delay the commencement or completion of Improvements,
shall be subject to the prior written approval of
Seller subject to the standard for approval and Purchase Price adjustment
provided for in Section 6(c) and 6(d), respectively, in the Purchase Agreement;
any such changes approved by Seller shall be a "Change Order" hereunder. Before
any such design and/or construction changes are made, Buyer shall pay to Seller
the full costs to be incurred by Seller in connection with such Change Order if,
and to the extent, the aggregate cost of all Change Orders exceeds $3,000,000.
Any such Change Order funded by Seller shall be a basis for adjustment of the
Purchase Price pursuant to Section 6(d) of the Agreement to which this Work
Letter is attached as an exhibit. Seller and Buyer shall hold weekly
construction meetings during the development of the Project and shall cooperate
in good faith during the weekly meetings to review and agree upon Change Orders.
In those instances in which proposed revisions to Seller's Plans result from a
Change Order, Seller shall cause the Seller's contractor, if applicable, to
determine the additional cost or savings from such Change Order, and Seller
shall promptly so notify Buyer. The additional costs or savings resulting from
such Change Orders (and the time impact of said Change Order, if any) shall be
supported by detailed trade cost breakdowns prepared by Seller's Contractor.
Buyer shall, within five (5) business days after such notification by Seller,
inform Seller in writing whether or not Buyer desires to proceed with such
Change Order. In the event that Buyer fails to inform Seller within such five
(5) day period that Buyer desires to proceed with such Change Order, Seller
shall not make any changes(s) to the Improvements included in such Change Order.
If Buyer informs Seller within such five (5) day period that Buyer does wish to
proceed with the proposed Change Order, the proposed Change Order shall be
incorporated in the Improvements if applicable thereto and Seller's contractor
shall proceed with the work covered by the Change Order and Buyer shall be
responsible for all costs and expenses incurred in connection therewith as
aforesaid. The Seller shall pass through to Buyer the Seller's contractor's
percentage mark-up (which shall not be greater than the mark-up charged to
Seller) for overhead and profit (which shall include all charges for general
conditions) for Change Orders to the Improvements without additional mark-up
from Seller. All Change Orders shall be in writing and shall be on such AIA form
as required by Seller and/or Seller's contractor. Buyer shall evidence in
writing it's approval of such Change Order prior to Seller's approval of same.
6. Substantial Completion. For purposes of this Work Letter
and the Purchase Agreement, the Improvements shall be deemed "substantially
complete" at such time as (i) Seller has completed work in accordance with
Seller's Plans and in compliance with all legal requirements applicable to the
Improvements at the time the permits where obtained for the construction thereof
subject to completion and correction of items on Seller's architect's punch
list, and landscaping, (ii) Seller has assured Buyer access to the Building
(e.g. all concrete/asphalt paving and hard scape work is complete), and (iii)
Seller is diligently prosecuting the completion of landscaping. Upon Buyer's
request, if a certificate of shell completion or similar certification is
available from the City of Sunnyvale in connection with the Improvements,
without incurring any additional cost or causing delays to the Improvements or
Buyer Improvements, Seller shall use commercially reasonable efforts to obtain
such certification after completion of the Improvements and deliver a copy to
7. Buyer Delays. If substantial completion of the Improvements
is delayed due to any of the following (collectively, "Buyer Delays"), then the
delay shall be included in the Milestone Delay Extension and the Purchase Price
shall be subject to adjustment pursuant to
Section 6(d) of the Purchase Agreement: (i) Buyer's failure to timely submit any
items required by this Work Letter, including, without limitation, the space
plan, supporting drawings and specifications and pallet of interior colors and
finishes; (b) Buyer's requested changes to the Improvements pursuant to any
Change Order(s); or (c) Buyer's failure to comply with Seller's contractor's
schedule. No Buyer Delay shall be deemed to have occurred unless and until
Seller has given written notice to Buyer specifying the action or inaction which
Seller contends constitutes a Buyer Delay. If such action or inaction is not
cured within one (1) business day after Buyer's receipt of such notice, then a
Buyer Delay, as set forth in such notice, shall be deemed to have occurred
commencing as of the date Buyer received such notice and continuing for the
number of days the substantial completion of the Improvements was in fact
delayed as a direct result of such action or inaction.
8. Seller Delay. The term "Seller Delay" as used in this Lease
or this Work Letter shall mean the extent of any delay in the design or
construction of the Buyer Improvements which is due to the following: (1) delay
in the giving of authorizations or approvals by Seller beyond the time periods
provided for herein or in the Lease; (2) delay attributable to the refusal of
Seller, its agents or contractors to permit Buyer, its agents or contractors,
access to and use of the Building and any Building facilities or services after
the Initial Buyer Work Date; (3) delay attributable to Seller giving Buyer
incorrect or incomplete Building requirements or Seller Plans, or revisions made
to such Seller Plans subsequent to the delivery of such items to Buyer; and (4)
failure of Seller to deliver Seller's Plans to Buyer on or before July 1, 1998.
No Seller Delay shall be deemed to have occurred unless and until Buyer has
given written notice to Seller specifying the action or inaction which Buyer
contends constitutes a Seller Delay. If such action or inaction is not cured
within one (1) business day after Seller's receipt of such notice, then a Seller
Delay, as set forth in such notice, shall be deemed to have occurred commencing
as of the date Seller received such notice and continuing for the number of days
the substantial completion of the Buyer Improvements was in fact delayed as a
direct result of such action or inaction.
9. Force Majeure Events. The term "Force Majeure Events," as
used in the Lease or this Work Letter shall mean any delay in the completion of
the Improvements which is attributable to any: (1) actual delay or failure to
perform by the applicable party attributable to any strike, lockout or other
labor or industrial disturbance (whether or not on the part of employees of
either party hereto), civil disturbance, future order claiming jurisdiction, act
of the public enemy, war, riot, sabotage, blockade, embargo, inability to secure
customary materials, supplies, or labor through ordinary sources by reason or
regulation or order of any governmental or regulatory body; (2) delay
attributable to lightning, earthquake, fire, storm, hurricane, tornado, flood,
washout, rain, severe weather, explosion, or any other similar industry-wide or
area-wide cause beyond the reasonable control of the party from whom performance
is required, or any of its contractors or other representatives. Except as
specifically limited in this Work Letter, any prevention, delay or stoppage due
to any Force Majeure Event shall excuse the performance of the party affected
for a period of time equal to any such prevention, delay or stoppages (except
the obligations of either party to pay money, other than rent, pursuant to this
Lease). No Force Majeure Event shall be deemed to have occurred unless and until
the party claiming such Force Majeure Event has provided written notice to the
other party specifying the action or inaction
that such notifying party contends constitutes a Force Majeure Event within five
(5) business days of the occurrence of such event.
10. Billing. Buyer shall pay to Seller all amounts payable by
Buyer within thirty (30) days after billing by Seller. Bills may be rendered
during the progress of the work so as to enable Seller to pay its general
contractor, architect or engineers without advancing Seller's funds for changes
to the Base Building Improvements, though such progress billings shall only be
based on the extent to which the work is completed.
11. Insurance. During the course of construction, Seller shall
require its contractors and architects to obtain and maintain in force Broad
Form Comprehensive General Liability insurance (including, without limitation,
insurance against completed operations liability for losses occurring within
three (3) years after the completion of the Work) with coverage for explosion,
collapse, and underground damage, against claims arising out of bodily injury,
personal injury, or death and from damage to or destruction of property of
others, including, without limitation, loss of use thereof, and including,
without limitation, the liability of Seller or the applicable contractor or
architect arising out of the activities of all subcontractors, and each of them,
with a combined single limit of not less than One Million Dollars ($1,000,000)
for any one accident and/or occurrence and/or series of accidents or occurrences
arising out of any one event. Such insurance shall include Broad Form Property
Damage and Independent Contractors Coverage. Such insurance shall be primary and
not subject to any contribution from any insurance carried by Seller.
12. Buyer's Improvements. In the event that Buyer wishes to
commence constructing additional improvements within the Improvements to be
constructed by Seller ("Buyer's Improvements") prior to substantial completion
of the Improvements by Seller, the terms and conditions of this paragraph 12
shall apply. Buyer shall use Devcon Construction as its general contractor for
the Buyer Improvements or some other contractor with an equivalent reputation
and bonding capability reasonably approved by Seller ("Buyer's Contractor").
Buyer shall direct and authorize Buyer's Contractor to keep Seller fully
informed of the construction process for the Buyer Improvements and to provide
Seller with access to all documentation and other information in Buyer's
Contractor's possession or control regarding construction of the Buyer
Improvements, provided that Seller shall not be obligated to monitor or inspect
construction of the Buyer Improvements or any information in connection
All Buyer Improvements shall be constructed by Buyer's
Contractor. Installation of all Buyer Improvements shall be coordinated with
Seller's contractor's schedule for the Base Building Improvements, and shall be
handled in such a manner as to maintain harmonious labor relations and not
interfere with or delay the work of Seller's contractors. In addition, at
Seller's request all Buyer Improvements shall be constructed using union labor.
All Buyer Improvements furnished and installed by Buyer shall not cause Seller's
contractor to be dependent upon Buyer's work in order for Seller's contractor to
complete his work. Buyer's contractors, subcontractors and labor shall be
subject to approval by Seller which approval shall not be unreasonably withheld
or delayed and shall be subject to the reasonable administrative supervision of
Buyer's general contractor and reasonable rules of the site. Buyer shall give
Seller full access and entry to the Premises in order to complete the Base
Building Improvements. Buyer shall not be charged any fee for Seller's review of
the plans, drawings and specifications or any oversight of the construction of
the Buyer Improvements.
Buyer shall keep the Property free and clear of all lien
claims arising in connection with Buyer's Improvements. Any delay experienced by
Seller as the result of Buyer's construction of Buyer's Improvements shall
constitute a Buyer's Delay (subject to the notice and cure provisions of section
7 above) for the purposes of this work letter. In the event the Purchase
Agreement is terminated by Buyer pursuant to the terms and conditions thereof,
except due to Seller's intentional breach at the election of Seller, Buyer shall
immediately remove any and all of Buyer's Improvements that Seller reasonably
determines to be of no value or of negative value in connection with the use of
the Property by Seller; provided, however, at any time prior to commencement of
construction of Buyer's Improvements, Buyer may submit to Seller its plans and
specifications for Buyer's Improvements and request that Seller designate in
writing within fifteen (15) days from receipt of such written request, which
portion of the proposed Buyer's Improvements meet the foregoing standard
requiring removal. Seller shall have no obligation to pay Buyer for any of
Buyer's Improvements in the event of termination of the Agreement for any reason
BASE BUILDING IMPROVEMENT PLANS
[Plan index to be attached from submittal set]
REVISED SITE PLAN
[Plan index to be attached from submittal set]
APPROVED BUYER PLAN GUIDELINES
[To be forthcoming pursuant to the terms outlined below. Typically, the easiest
manner to do this is for Buyer to attach a conceptual, softline plan that would
Seller and Buyer shall endeavor to agree upon parameters concerning the contents
of this Exhibit. However, the parties have no obligation to so agree. In the
event that Buyer believes that the parties are unable to agree upon such
parameters, Buyer shall have the option to terminate the Lease by providing
Seller written notice of its election to do so within two (2) weeks of the
execution date of the Lease.
Network Appliance, Inc.
Attn: [corporate officer]
Re: Acknowledgment of Initial Buyer Work Date under the Lease Agreement
by and between 495 Java Drive Associates, L.P., and Network Appliance,
Inc., dated as of ______________, 1998 (the "Lease")
This letter will confirm that for all purposes of the Lease,
the Initial Buyer Work Date (as defined in Paragraph 3(a) of the Lease) is
Please acknowledge your acceptance of this letter by signing
and returning a copy to the undersigned.
Very truly yours,
495 Java Drive Associates, L.P.,
a California limited partnership
By: M-D Ventures, Inc.,
a California corporation
Its General Partner
Accepted and Agreed:
Network Appliance, Inc.,
a Delaware corporation
[TO FOLLOW FROM LENDER, SUBJECT TO BUYER'S REASONABLE REQUIREMENTS]
FORM OF BUYER ESTOPPEL CERTIFICATE
TO: __________________________ , OR ASSIGNEE ("LENDER"), AND/OR WHOM ELSE IT MAY
THIS IS TO CERTIFY THAT:
1. The undersigned is the lessee ("Buyer") under that certain lease dated
______________, 19____ , ("Lease"), by and between ___________________
________________ as lessor ("Seller") and ____________________________
as Buyer, covering those certain premises commonly known and designated
as __________________ ("Premises").
2. The Lease has not been modified, changed, altered, assigned,
supplemented or amended in any respect (except as indicated below; if
none, state "none"). The Lease is not in default and is valid and in
full force and effect on the date hereof. The Lease is the only Lease
or agreement between the Buyer and the Seller affecting or relating to
the Premises. The Lease represents the entire agreement between the
Seller and the Buyer with respect to the Premises ________________.
3. The Buyer is not entitled to, and has made no agreement(s) with the
Seller or its agents or employees concerning free rent, partial rent,
rebate of rent payments, credit or offset or deduction in rent, or any
other type of rental concession, including, without limitation, lease
support payments or lease buy-outs (except as expressly provided in the
Lease or as indicated below; if none, state "none").
4. The Buyer has accepted the Premises, and opened for business in the
Premises on _____________________, 19__. The Lease term began
_____________________, 19__. The termination date of the present term
of the Lease, excluding unexercised renewals, is ___________________,
5. The Buyer has paid rent for the Premises for the period up to and
including ______ , 19__ . The fixed minimum rent and any additional
rent (including the Buyer's share of tax increases and cost of living
increases) payable by the Buyer presently is $__ per month. No such
rent has been paid more than one (1) month in advance of its due date,
except as indicated below (if none, state "none"). The Buyer's security
6. To the best of Buyer's knowledge (which means the current, actual
knowledge of the signatory for Buyer, who is the person responsible at
Buyer for applicable matters): (i) no
event has occurred and no condition exists which, with the giving
notice or the lapse of time or both, will constitute a default under
the Lease; and (ii) the Buyer has no existing defenses or offsets
against the enforcement of this Lease by the Seller.
7. The Buyer has received or will receive payment or credit for Buyer
improvement work in the total amount of $_______________ (or if other
than cash, describe below; if none, state "none"). Except as noted
below, all conditions under this Lease to be performed by the Seller
have been satisfied. ___________________________________.
8. Except as provided in the Lease, the Buyer has no outstanding options
or rights of first refusal to purchase the Premises or any part thereof
or all or any part of the real property of which the Premises are a
9. No actions, whether voluntary or otherwise, are pending against the
Buyer or any general partner of the Buyer under the bankruptcy laws of
the United States or any state thereof.
10. The Buyer has not sublet the Premises to any sublessee and has not
assigned any of its rights under the Lease, except as indicated below
(if none, state "none"). No one except the Buyer and its employees
occupies the Premises. ________________________________ .
11. The address for notices to be sent to the Buyer is as set forth in the
12. To the best of Buyer's knowledge, Buyer's and Buyer's sublessee's and
assignee's use, maintenance or operation of the Premises complies with,
and will at all times comply with, all applicable federal, state,
county or local statutes, laws, rules and regulations of any
governmental authorities relating to environmental, health or safety
matters (being hereinafter collectively referred to as the
13. The Premises have not been used and the Buyer does not plan to use the
Premises for any activities which, directly or indirectly, involve the
use, generation, treatment, storage, transportation or disposal of any
petroleum product or any toxic or hazardous chemical, material,
substance, pollutant or waste except as permitted by the lease.
14. Buyer has not received any notices, written or oral, of violation of
any Environmental Law or of any allegation which, if true, would
contradict anything contained herein and there are no writs,
injunctions, decrees, orders or judgements outstanding, no lawsuits,
claims, proceedings or investigations pending or threatened, relating
to Buyer's or Buyer's sublessee's or assignee's use, maintenance or
operation of the Premises, nor is Buyer aware of a basis for any such
15. (INCLUDE THIS PARAGRAPH FOR LOAN TRANSACTIONS.) The Buyer acknowledges
that all the interest of the Seller in and to the Lease is being duly
assigned to Lender, and that pursuant to the terms thereof, all rent
payments under the Lease shall
continue to be paid to the Seller in accordance with the terms of the
Lease unless and until the Buyer is notified otherwise in writing by
Lender or its successors or assigns. Buyer is hereby authorized and
directed by Seller to comply with any written direction of Lender
concerning payment of Rent and no such compliance will give rise to any
default by Buyer under the Lease.
It is particularly noted that:
(a) Under the provisions of this assignment, the Lease cannot
be terminated (except as expressly provided in the Lease) or
modified in any of its terms, or consent be given to the
release of any party having liability thereon, without the
prior written consent of Lender or it successors or assigns,
and without such consent, no rent may be collected or accepted
more than one (1) month in advance.
(b) The interest of the Seller in the Lease has been assigned
to Lender for the purposes specified in the assignment.
Lender, or its successors or assigns, assumes no duty,
liability or obligation whatsoever under the Lease or any
extension or renewal thereof.
(c) Any notices sent to Lender or its affiliates should be
sent by registered mail and addressed as follows:
16. Buyer agrees to give any Mortgagee and/or Trust Deed Holders
("Mortgagee"), by registered mail, a copy of any notice of default
served upon the Seller, and Lender shall have the cure rights expressly
provided in Paragraph 21 of the Lease.
17. This certification is made to induce Lender to make certain fundings,
knowing that Lender relies upon the truth of this certification in
disbursing said funds.
18. The undersigned is authorized to execute this Buyer Estoppel
Certificate on behalf of the Buyer.
DATED THIS DAY OF _______, 19_________.
THE UNDERSIGNED HEREBY CERTIFIES THAT THE CERTIFICATIONS SET FORTH ABOVE ARE
TRUE AS OF THE DATE HEREOF.
[PREAPPROVED FORM OF SNDA AGREEMENT TO BE ATTACHED]
RULES AND REGULATIONS
1. Sidewalks, exits, entrances, elevators, escalators and
stairways shall not be obstructed by Buyer or used by Buyer for any purpose
other than for ingress to and egress from the Premises. Buyer, and Buyer's
employees or invitees, shall not go upon the roof of the Building, except as
authorized by Seller or pursuant to Paragraph 46 of the Lease.
2. All curtains, draperies, blinds, shutters, shades, screens
or other coverings, awnings, hangings or decorations shall be attached to, hung
or placed in, or used in connection with, any exterior window, door or patio on
the Premises, if any, shall be subject to Seller's approval, which shall not be
3. If Buyer shall alter any lock or access device or install a
new or additional lock or access device, Buyer shall in each case furnish Seller
with a key for any such lock to the extent Seller would be entitled to such key
under the Lease.
4. Upon the termination of the tenancy, Buyer shall deliver to
Seller all the keys or access devices for the Building, offices, rooms and
toilet rooms which Buyer shall have had made.
5. The toilet rooms, toilets, urinals, wash bowls and other
apparatus shall not be used for any purpose other than that for which they were
constructed and no foreign substance of any kind whatsoever shall be thrown
therein, and the expense of any breakage, stoppage or damage resulting from the
violation of this rule by Buyer or Buyer's employees or invitees shall be borne
6. Animals or birds shall not be brought or kept in or about
the Premises or the Building, other than seeing-eye dogs or other such animals
that assist handicapped individuals.
7. Buyer shall not install any radio or television antenna,
loudspeaker or any other device on the exterior walls or the roof of the
Building except as expressly permitted by the Lease.
8. Buyer shall not lay linoleum, tile, carpet or any other
floor covering so that the same shall be affixed to the floor of the Premises in
any manner except as approved in writing by Seller. The expense of repairing any
damage resulting from a violation of this rule by Buyer or Buyer's contractors,
employees or invitees or the removal of any floor covering shall be borne by
9. Buyer shall not place a load upon any floor of the Premises
which exceeds the load per square foot which such floor was designed to carry
and which is allowed by law. Buyer may hang pictures on walls in the Premises.
Any damage to the walls caused by molley bolts, double sided tape, or like
hanging materials, will be repaired by Buyer.
10. Buyer shall store all trash and garbage within the
interior of the Premises or in the appropriate trash collection areas outside of
the Premises. No material shall be placed in the trash boxes or receptacles if
such material is of such nature that it may not be disposed of in the ordinary
and customary manner of removing and disposing of trash and garbage in the
jurisdiction in which the Premises is located, without violation of any law or
ordinance governing such disposal.
11. Buyer shall comply with all safety, fire protection and
evacuation procedures and regulations established by any governmental agency.
12. Buyer assumes any and all responsibility for protecting
the Premises from theft, robbery and pilferage, which includes keeping doors
locked and other means of entry to the Premises closed, unless caused by the
gross negligence or willful misconduct of Seller, its agents, servants, or
employees ("Seller Parties").
13. Buyer shall be responsible for the observance of all of
the foregoing Rules and Regulations by Buyer's employees, agents, clients,
customers, invitees and guests.
14. Unless otherwise defined, terms used in these Rules and
Regulations shall have the same meaning as in the Lease.
REQUIRED CONDITION OF PREMISES UPON SURRENDER
Upon termination of the Lease, the Premises shall be returned
to Seller with all Building Systems and elevator, fire and gas systems in good
working order and maintained with any necessary repairs completed in the
reasonable opinion of Seller's subcontractor, and all operating manuals and
maintenance records with respect to such systems shall be delivered to Seller.
All space in the Premises shall be clean and well-maintained with walls freshly
painted as necessary (or touched-up, if acceptable to Seller in its reasonable
discretion), and carpet shampooed and presentable for re-leasing. Any damaged or
unpresentable carpet shall be replaced. All window coverings shall be cleaned
and any damaged coverings repaired or replaced. Any damaged ceiling tiles shall
be replaced and all light fixtures shall be fully operational and clean. All
doors shall be presentable and damaged doors repaired or replaced. Bathrooms
shall be freshly mopped and all tile surfaces cleaned. Any damaged bathroom
partitions or fixtures shall be repaired or replaced. The exterior and interior
of all windows shall be washed and all interior partition glass shall be
cleaned. If Buyer is obligated to remove or restore any Buyer Improvements or
Alterations upon termination or expiration of the Lease pursuant to Paragraph
8(d) or (e) of the Lease or Paragraph 6 of the Work Letter, the affected area
will be returned to Seller in the form of open office space in the condition
FORM OF LETTER OF CREDIT
[TO BE PROVIDED BY BUYER FOR REVIEW BY SELLER PRIOR TO LEASE EXECUTION]
BUYER'S HAZARDOUS SUBSTANCES DISCLOSURES
[TO BE PROVIDED BY BUYER FOR SELLER'S REVIEW PRIOR TO LEASE EXECUTION]
ADDENDUM TO AGREEMENT OF PURCHASE AND SALE
Notwithstanding anything to the contrary in the Agreement of
Purchase and Sale between Network Appliance, Inc. ("Buyer") and 495 Java Drive
Associates, L.P. ("Seller"), (i) Buyer warrants that it has authority to
execute, deliver and perform the Agreement of Purchase and Sale and (ii) Seller
shall be entitled to terminate the Agreement of Purchase and Sale at any time
after July 10, 1998 if, prior to such termination Buyer has failed to deliver to
Seller its Board of Directors Resolution certified by the Secretary or Assistant
Secretary of Buyer authorizing the transactions contemplated by the Agreement of
Purchase and Sale. Upon such termination Seller shall return Buyer's Deposit.
NETWORK APPLIANCE, INC.
By: /s/ CHRIS CARLTON
Its: Vice President
495 JAVA DRIVE ASSOCIATES, L.P.
By M-D Ventures, Inc.
By: /s/ JEFFREY JOHNSON
This Indemnification Agreement is executed as of June 15, 1998
by and between Network Appliance, Inc., a Delaware Corporation ("Network") and
495 Java Drive Associates, L.P., a California limited partnership ("Java").
a. Java owns the property located at 495 Java Drive,
Sunnyvale, California ("Property").
b. Java is in the process of constructing a four story
building consisting of approximately One Hundred Twenty-Six Thousand Seven
Hundred Sixty (126,760) square feet ("Improvements"). The Improvements are being
constructed by Devcon Construction Company ("Devcon").
c. Network and Java have executed that certain Agreement
Of Purchase And Sale dated as of June 11, 1998 for the purchase by Network of
the Property ("Purchase Agreement").
d. The capitalized terms not otherwise defined herein
shall have the meanings given in the Purchase Agreement.
e. Network wishes to review the plans and specifications
for the Improvements to consider changes therein. Under the terms and conditions
of the Purchase Agreement the additional costs of changes are to be borne by
Network. In order to minimize the additional costs associated with such changes
Network has determined that it would be to its advantage to cause Devcon to stop
construction as of the date hereof and to do only such construction as Network
f. Java is willing to allow Network to stop the Devcon
construction and limit its construction to only those portions of the work
authorized by Network in accordance herewith if, and only if, Network
indemnifies Java on the terms and conditions of this Indemnity Agreement for the
costs associated therewith.
2. Devcon Construction. Java shall instruct Devcon to stop
construction as of June 16, 1998 and to limit its construction to only the
portions of work authorized by Network (collectively "Stop Work Notice") until
the earlier of (i) written notice delivered by Network to Java notifying Java
that it wishes to withdraw the Stop Work Notice or (ii) written notice by Java
delivered to Network that it has withdrawn the Stop Work Notice following
termination of the Purchase Agreement or after September 14, 1998.
3. Indemnification. Network shall be obligated to pay Java the
following costs and expenses associated with the Stop Work Notice:
(a) All increased costs of construction of the Improvements
charged by Devcon in connection with the Stop Work Notice as
evidenced by appropriate invoices and supporting information
supplied by Devcon. Java agrees to cooperate with Network in
reviewing and approving such charges.
(b) The sum of $2,323 per day for the period that substantial
completion of the Improvements is delayed by the effect of the
Stop Work Notice as determined by Devcon and reasonably
approved by Java. Unless and until substantial completion of
the Improvements occurs it shall be presumed that the number
of days of delay caused by the Stop Work Notice shall be the
number of days from June 16, 1998 until the day proceeding the
date Devcon commences pouring foundations (ie the same stage
of construction that existed on June 16, 1998) ("Presumed
Delay Period"). If the purchase and sale contemplated by the
Purchase Agreement fails to occur for any reason whatsoever,
the number of days of delay shall be the Presumed Delay
Period. If the purchase and sale contemplated by the Purchase
Agreement is completed the number of days of delay for the
computation required by this sub-paragraph (b) shall be the
lesser of (i) the Presumed Delay Period or (ii) the number of
days beyond March 17, 1999 that substantial completion of the
Improvements (as defined in the Purchase Agreement) occurs.
4. Payment. Unless and until the Purchase Agreement is
terminated or the Closing Date arrives and Close of Escrow is not completed on
the Closing Date the amounts that Network is obligated to pay pursuant to this
Indemnification Agreement shall be treated as a Change Order under the Purchase
Agreement and credited to the first $3,000,000 of Change Orders to be financed
by Java and which are to result in an adjustment to the Purchase Price at Close
of Escrow. In the event the Purchase Agreement is terminated for any reason
whatsoever and/or the Closing Date arrives and Network fails to purchase the
Property for any reason whatsoever, the amounts payable by Network to Java
hereunder shall be due and payable within ten (10) days written notice given
pursuant to the notice procedure set forth in the Purchase Agreement.
5. Attorneys fees; Arbitration. In the event of any litigation
or arbitration regarding the rights and obligations under this Agreement the
prevailing party shall be entitled to recover, in addition to damages,
reasonably attorney's fees, expert witness fees and court costs. Any controversy
or claim arising out of this Agreement shall be settled by arbitration in
accordance with the rules of the American Arbitration Association for the
arbitration of commercial disputes, and judgement on the award rendered by the
Arbitrator(s) may be entered in any court having jurisdiction. the prevailing
party in such arbitration shall be entitled to attorney's fees and costs.
6. Separate and Independent Obligations. The obligations of
Network are entirely separate and independent of any and all of the rights and
obligations of the parties under the Purchase Agreement or any other agreement
between the parties hereto.
IN WITNESS WHEREOF the parties hereto have executed this
Indemnity Agreement as of the date and year set forth above.
Network Appliance, Inc.,
a Delaware Corporation
/s/ CHRIS CARLTON
by: Chris Carlton
its: Vice President
495 Java Drive Associates, L.P.,
M-D Venture, Inc., a California
Corporation, its General Partner
/s/ JEFFREY JOHNSON
by: Jeffrey Johnson